A Study of Construction Delay for Turnkey Project of Urban Land Readjustment
碩士 === 國立交通大學 === 土木工程學系 === 101 === The delay-dispute issue is one of the most common problems in public building construction. This study focuses on the turnkey project of urban land readjustment, and the dispute of concurrent delay and ownership of float caused by the owner's cooperative obl...
| Main Author: | |
|---|---|
| Other Authors: | |
| Format: | Others |
| Language: | zh-TW |
| Published: |
2012
|
| Online Access: | http://ndltd.ncl.edu.tw/handle/11063128201124941568 |
| Summary: | 碩士 === 國立交通大學 === 土木工程學系 === 101 === The delay-dispute issue is one of the most common problems in public building construction. This study focuses on the turnkey project of urban land readjustment, and the dispute of concurrent delay and ownership of float caused by the owner's cooperative obligation of obtaining land. In the past, there was seldom study which combines construction progress theory and law to discuss the delay-dispute issue. Now, the engineering project has been more complex than before. Therefore the court confronts the dispute of concurrent delay and ownership of float more and more. Since the apportionment of responsibilities of concurrent delay to the owner and the contractor is a difficult task, the court usually trusts the professionals to review and estimate.
This study uses construction delay analysis techniques to analyze the reality case and verify the applicability of all techniques. This study also uses questionnaire to analyze the crucial delay factors of the turnkey project of urban land readjustment.
|
|---|